Renovation contract template - a detailed study of the model (for reference only)
One of the reasons I chose Chuangshi Company is that the decoration contract can be signed in accordance with the 3331 method advocated by the Institute of Excellence, that is, 30% of the material entering the market, 30% of the mid-term acceptance, and 30% of the final acceptance, but the real company is The 10% payment time is different from what I expected (introduced on the Chuangshi company website). I thought it was the last 10% after six months or one year. I found that the thought was perfect. The real requirement was to pay the final 10% within three days after the acceptance. Thinking about the reputation of creating a tall sledgehammer is so good. There will be problems in the future. He will also repair it for me, so I will not call this truth.
The Chuangshi Company used the contract for the Beijing Family Home Decoration Project Construction Contract (2003). In the ointment, the text of the contract sent to me was too bad and there were countless typos. Hey, I just had to do editing and typesetting to sign a renovation contract like everything.
After careful study of the 2003 version of the contract, it was found that it was indeed necessary to sign additional clauses. After all, some of the responsibilities were not involved. After negotiating with the Sledgehammer, I did not sign the supplementary agreement alone, but put the relevant clauses into other contractual matters.
After studying the 30 supplementary agreements posted by Ninghai, I found out that the TXs are very powerful. The supplementary clauses basically bound Party B (decoration companies), and there was basically no responsibility for Party A. We can see that TX is How worried is the quality of the decoration of the house, and there is no way to solve the problem if it is out of question. The provisions in the supplementary agreement must not be ignored. In contrast, I am still more practical and realistic. I have tried to make adjustments to the terms that Party A could not achieve (but it is still beneficial to Party A), and it has been streamlined into 13 articles (such as other commitments). 15.1, I think I can't start the next process until all processes are accepted. So I only agreed on three stages of A, material approach B, mid-project acceptance C, and overall project completion acceptance. After all, these three stages It must be that I must appear, or how to pay the wages.) The other clauses are not explained one by one. Let's see for yourself.
In addition, on the basis of the original five attachments, I added two attachments for the copy of the foreman’s ID card and the project change order. The first is to say that it is also a form, the second is more critical, there is no sign adjustment on this list of fitting-out projects, I have the right not to give money (in other matters agreed to 15.9).
Below, attach a specific contract text for your reference.
Beijing Family Room Decoration Project Construction Contract (2003 Edition)
Employer (Party A):_______________________
Contractor (Party B):_______________________
Contract No:_______________________
Beijing Municipal Administration for Industry and Commerce Produced in 2004
1. The decoration of family homes in the administrative area of ​​this Municipality shall apply to the text of this contract. This version of the contract text applies until the new version of the contract is released.
2. The project contractor (Party B) shall have a business license issued by the administrative department for industry and commerce and a construction enterprise qualification certificate issued by the competent authority of the construction industry.
3ã€Party A and Party B sign this contract directly, should be in two copies, and both sides of the contract shall hold one copy; where the contract is signed in each market of the city, it shall be in triplicate (A and B parties and the market organizer Hold a copy).
4. Commencement: After the two sides have completed the preliminary work through the design proposal, the first-phase project payment, and the completion of engineering technology, the commencement of operation of the materials and construction personnel shall be deemed as commencement.
5. Completion: The project contents agreed in the contract (including indoor air quality monitoring) are all completed, and acceptance by the contractor, supervision unit, and contractor will be considered as completion.
6. Acceptance of Acceptance: Contractors, supervision units, and contract-issuing parties shall be deemed to be qualified for inspection after they have signed and sealed the "Project Acceptance Receipt Form" or have not yet gone through the acceptance procedures but the enrollee has already used the equipment.
7. Extension of construction period: It means that the duration of the project will be extended accordingly if the project progress is not affected due to the responsibility of Party B. In case of delay of the construction period, Party B shall not be liable for breach of contract.
Beijing Family Room Decoration Project Contract Agreement Contracting Party (hereinafter referred to as Party A): _____________________________________
Attorney (Name): _________ Ethnicity: _______ Residence: _________________________
ID number: _______________ Telephone number: _____________ Mobile number: ________________________
Contractor (hereinafter referred to as Party B): _____________________________________
Business license number: ______________________ Address: _____________________________________
Legal representative: Telephone:
Representative delegates: Telephone:
Building qualification certificate number: __________________________________________
This project designer: Contact phone:________________________
Construction team leader: Telephone: _________________________
In accordance with the "People's Republic of China Contract Law" and other relevant laws and regulations, combined with the characteristics of decoration and decoration of family homes in this Municipality, Party A and Party B, on the basis of equality, voluntariness, and consensus, will contract Party B to Party A's family room. The related matters of the decoration and decoration project (hereinafter referred to as the project) are as follows:
The first project overview
1.1 Project location: _______________________________________________________
1.2 Project decoration area: ___________
1.3 Project Type: _________________________
1.4 Project content and practices (see quotation sheets and drawings).
1.5 Project contracting, take the following approach:
(1) Party B works and packs all materials (see Attachment 3).
(2)Party B includes the workmanship, the package includes some materials, and Party A provides the rest of the materials (see Annexes II and III).
1. 6 days of the project _________; (calculated on the actual working day)
Date of Commencement ________ Year ____ Month _____days (The third day after the first phase of construction is in place is the start date).
Completion date ________ years____months____days (acceptance acceptance date according to agreed acceptance standards is completion date).
1.7 (1) Contract price: The construction cost of this contract is (RMB) See the engineering quotation amount Capital letter: See the project quotation (2) The compilation quotation is based on the reference price of Beijing home decoration project, based on market economic actions Rules, in line with the principle of better prices, are agreed by both parties in the contract.
(3) The contract quotations shall be compiled with the material quality standards and the establishment of the safety and security process as the basis for determining the project price.
Article 2 Project Supervision If this project implements project supervision, Party A shall sign an "Engineering Supervision Contract" with an engineering supervision company approved by the construction administrative department, and the name, unit, contact information and supervision engineer of the supervision engineer. Responsibility, etc. inform Party B.
Article 3 Construction Drawings and Indoor Environment Design
3.1 The construction drawings are provided in the following ________ ways:
1. Party A shall design its own, and provide three copies of construction drawings and pre-evaluation calculations for indoor environmental pollution control. Party A shall hold one copy and Party B shall hold two copies.
2. Party A entrusts Party B to design and provides construction drawings and pre-evaluation calculations for indoor environmental pollution control in triplicate. Party A holds one copy and Party B holds two copies.
3.2 The design plans and drawings provided by both parties must meet the requirements of the "Guidelines for Pollution Control of Indoor Environment of Civil Building Projects" (GB50325-2001).
3.3 Both parties shall sign and confirm the construction drawings and the pre-evaluation calculations for indoor environmental pollution control.
3.4 Both parties shall not copy or transfer the construction drawings and design plans provided by the other party to third parties, nor may they be used for projects outside the contract.
Article 4 Party A's Work
4.1 Three days before the start of construction, conditions should be created for Party B's admission construction, so as not to affect the construction.
4.2 Water source, power supply and winter heating during construction period are provided free of charge.
4.3 Responsible for handling the start-up procedures of the house property department and the related expenses that should be paid by the owner.
4.4 Comply with the rules and regulations of the property management department.
4.5 Responsible for coordinating the relationship between the construction team and the neighborhood.
4.6 may not have the following behavior:
(1) It is forbidden to arbitrarily change the main body of the house and the bearing structure.
(2) It is forbidden to open windows, doors or enlarge the size of the original doors and windows on the external walls, and to remove the walls connecting the balconies and windows.
(3) It is forbidden to lay more than one centimeter of stone, masonry walls, and increase floor loads in the interior.
(4) It is forbidden to destroy the waterproof layer on the floor of kitchens and toilets, and to demolition of pipeline facilities such as heat, warm gas and gas.
(5) Other actions that forced Party B to violate the regulations.
4.7 Where it is necessary to deal with Section 4.6, the owner of the house shall submit an application to the housing management department. The original design unit or the design unit with the corresponding qualification level shall examine and issue a written certificate for the safe use of the alteration plan, and be approved by the housing management department. .
4.8 During the construction period, Party A still needs to use the house partially, and Party A should be responsible for coordinating with Party B to do a good job in defense and fire fighting.
4.9 Participate in the supervision of project quality and construction progress, participate in acceptance of engineering materials, inspection and acceptance of concealed projects, and completion acceptance.
Article 5 Party B Work
5.1 Strictly implement the safety construction operation specification, quality standards, safety operation regulations, fire prevention regulations, safety, durability, and complete the project content agreed in this contract on schedule.
5.2 Strictly implement the construction site management regulations of the municipal construction administrative department.
(1) Without the examination and approval procedures and reinforcement drawings of the housing management department, the building main body and load-bearing structure in the project shall not be demolished, the ground load of the building shall not be added, and the original indoor heating, heating and gas pipeline facilities shall not be altered.
(2) It shall not disturb people or pollute the environment. No decoration activities such as knocking, chiseling, planing, and drilling shall be conducted between 12:00 and 14:00, 18:00 and 8:00 of the next day.
(3) Party B shall be liable for repairs and losses due to the clogging, leakage, water cut, blackout, etc. caused by the decoration of the neighboring residential buildings.
(4) Responsible for the protection of finished furniture, equipment, and furnishing of furnishings in the living room.
(5) Ensure that the indoor and sewer pipes are open and the bathroom is clean.
(6) To ensure the cleanliness of the construction site, clean up the construction site after daily completion.
5.3 Provide Party A with the conditions for inspecting various standards, specifications, calculation books, reference prices, etc. involved in the signing and implementation of this contract by means of notifying the website and uniform publicity.
5.4 Party A is a national minority, Party B should respect its national customs and habits during the construction process.
Article 6 If there is a need to change the project contents agreed upon in the contract during the construction period, the two parties shall agree. The parties to the contract jointly sign a written change agreement and adjust the related engineering fees and duration. The engineering change agreement is used as the basis for the completion of the settlement and the extension of the construction period.
Article 7 Material Supply
7.1 It shall be provided in accordance with the material supply methods and contents as stipulated in the “Detailed List of Engineering Materials and Equipment†of the contracted home decoration prepared by Party B.
(1) Materials and equipment provided by Party A. Party A shall notify Party B before materials and equipment arrive at the construction site. Both parties shall jointly accept and process the materials, equipment quality and environmental protection standards and handle the handover procedures.
(2) The materials and equipment provided by Party B, Party B shall notify Party A before material and equipment arrive at the construction site. Both parties shall jointly accept and accept the materials, equipment quality and environmental protection standards, and Party A shall confirm the record.
(3) The building decoration materials provided by both parties must comply with the standards for "Limits for Indoor Decorations and Harmful Substances" issued by the General Administration of Quality Supervision, Inspection and Quarantine, and the qualified inspection reports provided by the professional inspection departments that have passed the examination and certification qualifications approved by the administrative department.
(4) If the parties have objections to the construction of the decoration materials, they need to be re-inspected. The cost of testing will be preceded by a meeting; if the materials are indeed unqualified, the testing costs will ultimately be borne by the other party.
(5) After the materials and equipment provided by Party A have been accepted and confirmed by Party B, the procedures for safekeeping and quality control in construction use shall be the responsibility of Party B.
Article 8 Delays in duration
8.1 Delay in the completion date for the following reasons, confirmed by Party A, the duration shall be postponed:
(1) Changes in engineering quantities or design changes; (2) Force majeure; (3) Other circumstances in which Party A agrees that the construction period will be postponed.
8.2 The delay in the date of completion due to the following reasons shall be postponed:
(1) Party A did not influence the construction period in accordance with the work that Party A was responsible for in the completion period of the contract;
(2) If Party A fails to pay for the project according to the contract, it will affect normal construction;
(3) Other circumstances that caused the delay of the construction period due to the responsibility of Party A.
8.3 Because Party B's responsibilities can't be completed on schedule, the construction period will not be postponed. Party B shall be responsible for the cost of rework due to Party B's reasons for the quality of the project. The construction period will not be postponed.
8.4 Judgment of delays caused by the duration of the work is based on the “word agreement recognized by both parties†as the basis for determining the responsibilities of both parties.
Article 9 Quality Standard
9.1 Renovation Indoor environmental pollution control shall be strictly implemented in accordance with the standards of the "Guidelines for Pollution Control of Indoor Environment of Civil Building Projects" (GB50325-2001).
9.2 The construction quality of this project shall be implemented according to the following ________ criteria:
(1) "Quality acceptance criteria for Beijing family home decoration project" (DBJ/T01-43-2003).
(2) "Quality Acceptance Standard for Beijing Advanced Building Decoration Engineering" (DBJ/T01-27-2003).
9.3 In case of completion and acceptance, the two parties disputed the project quality and indoor air quality, and applied for a professional inspection unit approved by the municipal construction administrative department and quality and technical supervision department to certify the project quality and indoor air quality. The costs associated with the certification process are borne by the responsible party.
Article 10 Project Acceptance and Warranty
10.1 Joint acceptance of the project quality in the following stages during the construction process:
(1) Acceptance of materials; (2) Acceptance of concealed works; (3) Acceptance of completion.
10.2 After the completion of the project, Party B informs Party A of the acceptance. Party A organizes acceptance within three days after receiving the acceptance notice. After acceptance, the two parties will complete the transfer formalities, settle the balance, sign the warranty, and submit the plan.
10.3 Before the completion of acceptance by the two parties, Party B shall be responsible for the protection of all the safety of the finished product and the site of the project.
10.4 The two parties have not gone through the check and acceptance procedures, and Party A shall not be allowed to check in. If Party A's unauthorized check-in is deemed as the acceptance contract, Party A shall bear the losses caused thereby.
10.5 Acceptance of Completion When the project quality, indoor air quality and economic aspects do not involve relatively large issues, the two parties can sign up after signing the "Agreement on Resolving Completion of Acceptance of Completion and Acceptance" (as an attachment to the acceptance check for completion).
10.6 Since the date of acceptance of the project by both parties, the warranty period for interior decoration works under normal conditions of use shall be two years, and the warranty period for leakage protection of kitchens and toilets with waterproof requirements shall be five years.
Article 11 Payment Methods for Construction Funds
11.1 After the signing of the contract takes effect, Party A will pay the construction fee to Party B according to the contract in the contract:
Payment times Payment time Payment rate according to project payment Amount to be paid The first time of material acceptance After acceptance, pay 30%
The second time the progress of the project is more than half of the acceptance and payment of 30%
The third acceptance of the completion acceptance payment 30%
The fourth time for completion acceptance, 10% will be paid within 3 days after the clearance
11.2 More than half of the progress of the project means that all the water and power lines in the project have been laid. The wall and top base are completed according to the process requirements. The doors, windows and fine wood and white products are basically completed to define the standard for the project.
11.3 After acceptance of the project, Party A shall review the project settlement statement submitted by Party B. If there is no objection within two days from the date of submission, Party A shall be deemed to have agreed to pay the balance of the project of Party B.
11.4 After the construction funds are fully settled, Party B issues a formal unified invoice to Party A as the main project certificate.
Article 12 Liability for breach of contract
12.1 If one party fails to perform the contractual obligation to the other party in accordance with the agreed contract, it shall be liable for compensation; if the party is punished for violating the relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.
12.2 If one of the parties is unable to continue to perform the contract, it shall promptly notify the other party and the responsible party shall bear the loss resulting from the cancellation of the contract.
12.3 Party A did not pay the second or third construction payment in accordance with the contractual time limit without any justified reason. Party B shall pay the penalty of 2% of the construction cost of the contract for each delay on one day.
12.4 As Party B's liability is delayed, the Party shall pay Party B the amount of breach of contract for the amount of 2% of the contract work for each delay.
12.5 As Party B's responsibilities lead to unqualified project quality and indoor air quality, Party B shall carry out rework repair, comprehensive treatment and compensation according to the following agreement:
(1) Party B must perform thorough rework to repair the site where the quality of the project is not qualified. The delayed delivery of the project due to rework is regarded as the delay of the same project. On each delay day, Party B shall pay Party B’s liquidated damages of the project’s construction cost of 2%.
(2) For unqualified indoor air quality, Party B must carry out comprehensive management. Due to governance, delayed delivery of the project is regarded as a delay in the same project. On each delay day, Party B pays Party B a penalty of 2% of the contractual construction cost.
(3) If the indoor air quality is still not up to standard and it is indeed the responsibility of Party B, Party B shall return the project money to Party A; after deducting the cost price of Party B’s non-compliance unrelated material, Party A does not meet the standard. If it is also responsible, Party B may reduce the return ratio accordingly.
Article 13 Method of Dispute Settlement In case of disputes arising under this contract, both parties shall negotiate or apply to the market sponsoring unit, consumer association, etc. for mediation. If consultation or mediation is not successful, it shall be resolved in the following ________ ways: The following two ways can only choose one).
(1) Proceeding to the ________________________ People's Court;
(2) Apply for arbitration from the ________________________ arbitration committee.
Article 14 Supplementary Provisions
14.1 This contract takes effect after both sides sign and seal the parties.
14.2 The project shall not be subcontracted after signing this contract.
14.3 Both parties may make changes or supplements to this contract in written form. However, if the change or supplement unreasonably reduces or exempts the liability of Party B as stipulated in this contract, the contract shall prevail.
14.4 The parties shall negotiate and settle the matter in accordance with the principle of fairness because the reasons for the non-imputability of the parties affect the performance of the contract or cause losses.
14.5 If Party B withdraws from the market, the market organizer shall first assume the liability for compensation; after the organizer assumes the responsibility, it shall have the right to seek compensation from Party B.
14.6 The contract is automatically terminated after it is completed.
Article 15 Other Matters
15.1 Party B shall notify Party A 48 hours in advance of the completion of the following key operations. Acceptance of the following procedures shall be followed by the next procedure: A. Material approach B, Mid-term acceptance C, and Overall project acceptance; The above sub-projects are not After the inspection and acceptance by the supervisor, Party B shall proceed with the construction of the next procedure without authorization. Party B shall be responsible for the loss of work materials. Party A shall bear Party A's delay in the construction period due to the failure to accept it on time.
15.2 The list of materials and quantities provided by Party B must be in conformity with the stipulations in “Party B's List of Supplying Engineering Materials and Equipment†(Annex 3), and present proof of purchase of materials to Party A (invoices or shopping papers or company's unified supply certificate). , Environmental certification, warranty certification, material sources and other related materials, Party A has the right to verify the authenticity of the materials to the construction headquarters or the manufacturer or distributor, if found that the materials provided by Party B are fake and shoddy products or do not meet the national, local, related The standards of the ministries and commissions and the specified products shall be promptly replaced by the products agreed upon in the contract or other qualified products approved by Party A at the same price, and shall be compensated to Party A at double the market price of the materials agreed in the contract; if Party B can propose The legally-recognized evidence is fully proven to be due to the supplier's responsibility. Party A can appropriately reduce the amount of compensation required according to the specific circumstances. Party B can pursue the corresponding responsibility to the material supplier. For the part that has been used for construction, Party A has the right to request Party B to dismantle and redo the work. The expenses incurred by Party B shall be borne by Party B.
15.3 Party B shall submit to Party A the list of materials purchased by Party A for the next process in advance, and provide the required amount of material that is roughly accurate (with a positive and negative difference of less than 10%). If Party B supplies the materials provided by Party A, if it causes a loss other than normal loss, Party B shall accompany Party A to purchase replenishment and bear the cost of related materials.
15.4 Materials and equipment provided by Party A shall be used only after acceptance by Party B through quality and quantity inspection. Once it is used, it shall be deemed as qualified. The resulting construction quality problems shall be borne by Party B. If Party B can prove after the fact that the quality problem is indeed caused by the unqualified material provided by Party A, and the quality problem cannot be discovered through conventional means such as observation, hand touch, and ruler measurements, the parties A and B shall bear 50 %Responsibility.
15.5 Party A shall deliver the materials to the downstairs for delivery, and Party B shall be responsible for handling the upstairs construction and transportation and related costs shall be Yuan.
15.6 The materials and equipment provided by Party A shall be used in this project. Without the consent of Party A, Party B shall not have the right to arbitrarily use or alter the materials and equipment provided by Party A.
15.7 During the construction period, Party A believes that Party B's construction personnel are not qualified to perform the decoration work, and have the right to require Party B to replace the construction personnel.
15.8 During the construction period, Party B has no right to change any design scheme and material quality. The design plan should include renderings, plans, and detailed dimensions. For any site production that is not on the above drawings, Party A has the right to refuse to pay for the project.
15.9 The project change shall be subject to the "Project Change Order", which shall specify the quantity and price of the change in detail, and be signed by both Party A and Party B as the settlement basis.
15.10 Party B shall conscientiously construct and shall not smoke, drink, spit, or cook in Party A's living room. At the same time, Party B shall not use any installed utensils such as cooking utensils, sanitary ware and other facilities and equipment, and keep the interior clean and sanitary. Party B shall be responsible for compensation and assume all responsibility if Party B’s negligence results in the damage of Party A’s facilities, equipment, and the completed parts of the room and any other losses.
15.11 The watering rate of the paint on the top of the wall shall be strictly controlled within the allowable range of the instructions. If Party B unauthorizedly increases the watering rate during the construction process, Party A has the right to require Party B to eradicate the original wall surface and repurchase the same type of heavy paint brush. All costs are the responsibility of Party B, and the duration of the project will not be postponed. Wall tiles and floor tiles shall not show empty drums, faulty stands, raised warpages, gaps, chromatic aberrations, bumps, etc. The emptying rate shall be less than or equal to 3%; otherwise, all costs incurred shall be borne by Party B, and the duration shall not be postponed.
15.12 Party A shall have the right to entrust the indoor environment quality testing unit identified by the country to independently perform indoor air quality testing on the premises of Party A after completion of Party B, and submit the test report (including formaldehyde, VOC, etc.) issued by the unit to Party A. . If the test result is unqualified, Party A and Party B must provide the environmental protection test report of their purchased materials. If the materials provided by Party A are in line with national standards, the testing cost shall be borne by Party B, and Party B shall be responsible for improving within 15 days after receiving Party A's notice. After the non-conformance item reaches the eligibility standard, the related expenses shall be borne by Party B, and Party B shall pay Party B's daily liquidated damages of 2%. If the rectification within 15 days is still unqualified, Party B will return all the project price of Party A and compensate for other losses.
15.13 After the acceptance of the project is completed, Party B shall provide Party A with a complete set of completion materials. Completion materials include: a) Completion drawings: mainly include the water supply and drainage as-built drawings and electrical as-built drawings. The drawings shall specify the location, depth, size, material, pipe diameter and wire diameter of the buried or darkly laid pipes. b) Engineering Change Order. c) Acceptance records and completion acceptance records for the engineering phase: mainly include material acceptance records, acceptance records for hydropower concealment projects, acceptance records for structures, skeletons, water shut-off test acceptance records, and completion acceptance records. d) Plates, timber, gypsum board, gypsum line, cement pressure board, veneer surface material, paint, paint, wall lining, all kinds of plastic, glass, cement, aluminum buckle board, water supply pipe, electric pipe, wire provided by Party B Materials such as product certification, quality inspection report, environmental testing report, instruction manual, etc. e) Project settlement statement and engineering warranty. If Party B’s completion information is not complete or it cannot be provided on time, Party A is entitled to suspend payment of settlement funds.
annex:
1, copy of the construction foreman ID card (front and back)
2, project quotation (including construction process description)
3, Party A supplies engineering materials, equipment schedules
4,Party B supplies engineering materials and equipment details
5, project change orders
6, project completion acceptance
7. Home Warranty Warranty Party A (signature): ________________ Party B (seal): _______________ Legal representative: _______________ Authorized representative: _______________
________ Year____ Month____ Day________ Year____ Month____ Day Market Organizer (seal):
Legal representative:
Attorney:
contact number:
________ Year __ Month _____ Days Don't forget to recommend this to friends on QQ/MSN (Jiangsu Construction Team, Xi'an Construction 20 Years Experience, Consulting Q1057545818 )
The entrance decoration Children's room decoration Interior decoration Decoration design Home decoration decoration company Interior decoration renderings Exterior wall decoration renderings Decoration decoration company look good Housing decoration renderings Toilet decoration renderings Glass bricks Kitchen wall tiles Crafts Glass furniture Toilet doors Glass doors Kitchen Glass sliding door bathroom door bathroom wall tile bathroom size bathroom floor tile bathroom waterproof price bathroom design bathroom waterproof bathroom door size
The working principle of a Medium Flow Peristaltic Pumpis like a snake swallowing an egg. The hose is constantly squeezed through the roller to make the hose generate pressure and push the liquid forward. Our designers make the Peristaltic pump head and hose fit perfectly by designing precise roller size and pump head structure. So as to achieve the purpose of accurate liquid metering transmission or filling
1. Clean and pollution-free: the fluid only passes through and touches the Peristaltic Pump hose.
2. High precision: constant current, reproducibility of up to 0.5%, and flow can be precisely adjusted.
3. Low shear force: It is an ideal tool for conveying shear-sensitive and corrosive fluids.
4. Corrosion resistance: it can transport various fluids, such as organic solvents and corrosive liquids.
5. Idling and dry operation: air or gas-liquid-solid three-phase mixed transportation can also be transported.
6. Possess self-priming ability: self-priming, no need to fill the pump, no need to empty.
7. With stop valve function, no siphon, no seals, stop valve and check valve function.
8. Two-way conveying function: reverse pumping and back-suction functions can be realized by changing the direction of the pump runner.
9. Simple maintenance: only need to replace the peristaltic pump hose, no valve and seal replacement.
Medium Flow Peristaltic Pump,Constant Flow Peristaltic Pump,Intelligent Accuracy Pump,24V Peristaltic Pump
Baoding Chuangrui Precision Pump Co., Ltd. , https://www.chuangruipump.com